표준 건설계약서(Construction Agreement) 사례,Duration and Place of Exhibition

소개글

표준 건설계약서(Construction Agreement) 사례,Duration and Place of Exhibition에 대한 보고서 자료입니다.

목차

표준 Construction Agreement사례

Article 1 (Name of Exhibition)
Article 2 (Duration and Place of Exhibition)
Article 3 (Work)
Article 4 (Period)
Article 5 (Approval of Material)
Article 6 (Price and Payment)
Article 7 (Responsibilities of Constructor)
Article 8 (Cancellation or Postponement)
Article 9 (Confidentiality)
Article 10 (Assignment)
Article 11 (Termination)
Article 12 (Force Majeure)
Article 13 (governing Law)
Article 14 (Arbitration)
Article 15 (Miscellaneous)

본문내용

t a written consent from other Party in advance.
Article 11 (Termination)
The Parties can terminate this Agreement in the event of the occurrence as follows:
(1) Owner or Contractor breaches a clause of this Agreement materially
(2) Contractor is proved to be in the lack of capacity of building installation for exhibition
(3) a money of support, etc., critical for holding this exhibition which must be executed in advance, fails to be received by Owner
(4) Contractor manifests no intent to carry out an obligation under this Agreement
(5) a justifiable cause for termination such as impairment to reputations of this exhibition by Contractor occurs
Article 12 (Force Majeure)
In the event that one Party fails to perform or delays obligations under this Agreement due to war, acts of god, strike, endemics, flood, earthquake, hurricane, fire, acts of government or any other reasonable causes beyond its control, the one Party shall not liable for the nonperformance or the delay.
Article 13 (governing Law)
Construction, effectiveness and performance of this Agreement shall be construed in accordance with the laws of Korea.
Article 14 (Arbitration)
Any dispute and difference of opinion incurred between the Parties arising from or in relation to this Agreement shall be resolved by arbitration which shall be held in Seoul,KoreainaccordancewiththeArbitrationRulesoftheKoreanCommercialArbitrationBoard.ArbitrationawardshallbefinalandbebindingonbothParties.
Article 15 (Miscellaneous)
The Parties agree to decide matters unspecified in the Agreement through mutual consultation pursuant to faith and integrity and sign on This Agreement in duplicate and keep one copy each.
Date:
“Principal”: [ ]
Address:
Signature:
[name of President]
“Agent: [ ]
Address:
Signature:
[name of President]

키워드

표준건설계약서사례,   Construction Agreement사례,   Construction Agreement,   사례,   건설,   건설계약서,   계약서,   건설 계약서